JavaScript Disabled

This site requires JavaScript Enabled to function properly. Please enable JavaScript or use a different browser that has JavaScript enabled.

Buying For Victoria
Skip to main content

Display Tender VHBA-21.1545-E-11 

If it's a selective tender, only the person that received the email notification and was invited to view the tender, can view and access it.

Use the forgot password feature, to access your account credentials at

Angliss Hospital Expansion Stage 2 – Main Works Building Contractor
Issued By Department of Health
Expression of Interest
Hospital buildings and structures



The Victorian Health Building Authority (“VHBA”), part of the Department of Health ("Principal"), is in
the process of redeveloping the Angliss Hospital operated by Eastern Health (EH).
This Invitation seeks to obtain Responses to an Expression of Interest ("EOI") from experienced and
capable contractors interested in performing the role of Fixed Price Lump Sum Contractor
("Contractor") for the construction and building commissioning of the main works component of the
The Project will be procured by the Principal and the funding for the Project will be provided by the
Victorian Government.
Department of Health and Human Services is Principal to the construction contracts and VHBA has
engaged Ontoit Pty Ltd as Project Manager and Superintendent for the construction contract between
the Principal and the Contractor to assist and manage the delivery of the Project to completion and
final certificate.
This Invitation is intended to:
· Outline the anticipated procurement process and timetable for the Project;
· Inform the market of the Project and the proposed delivery structure;
· Invite market participants to register demonstrable relevant experience, expertise and
capability to perform the Works;
· Inform prospective Respondents of the capabilities and Evaluation Criteria which will be
considered by the Principal in selecting which Respondents will be provided the opportunity to
participate in the Request for Tender ("RFT");
· Elicit responses from the market to be evaluated with a view to shortlisting Respondents to
proceed to the RFT stage of the Tender Process; and
· Seeks to identify any industry advice that should be considered in the scoping and delivery
requirements for the RFT documents.
Respondents should note that the information contained in this Section 1 - 'Information to
Respondents’ is subject to change at the Principal's discretion during any stage of the Tender Process.

Specification Documents 

You must be logged in to download documents.
  •    Expression of Interest (Main Works) - Angliss Hospital Expansion Stage 2 - Rev2 - 230613.pdf
    • Version 1 (15 June 2023)
    • Available by Download   (3 MB)
  •    Expression of Interest (Main Works) - Angliss Hospital Expansion Stage 2 - Rev 2 - 230613.docx
    • Version 1 (22 June 2023)
    • Available by Download   (3 MB)
  •    AHE MW EOI - Addendum 3 - 20230628.pdf
    • Version 1 (30 June 2023)
    • Available by Download   (150 KB)
  •    AHE MW EOI - Addendum 4 - 20230711.pdf
    • Version 1 (11 July 2023)
    • Available by Download   (144 KB)